Language:
Need Info?-Call Us
+39-0322-83-99-71
Terms & Conditions
PRICES
CGS reserves the right to change any pricing without notification
to the customer.
TERMS OF DELIVERY
CGS shall endeavor to initiate shipment and schedule delivery
as close as possible to Customer’s requested delivery
dates and Customer acknowledges that any delivery dates
provided by CGS are estimates only. CGS shall not be
liable for any delay in delivery or for failure to give notice
of such delay. Customer waives any right to cancel order
due to any such delay in delivery.
SHIPPING
All shipments by CGS are Ex-Works unless otherwise
agreed to in writing. Title and risk of loss to Products shall
pass to Customer upon delivery to the common carrier.
Customer is responsible for all freight, handling and insurance
charges which shall be in addition to the price
of the Products in the Quote. In no event shall CGS have
any liability for loss or damage during shipment. Customer
shall accept and pay for partial shipments of Products.
PACKAGING
Quoted pricing includes all standard packaging. Extra
packaging may be requested by the customer and provided
at extra cost borne by the customer. Extra packaging
is to be excluded from any refund if made by CGS.
CONDITIONS OF PAYMENT
If payment is not recieved in period specified by CGS with
customer’s order, CGS may charge interest entitled to it
under law. CGS reserves the right to withhold subsequent
deliveries until all outstanding payments are settled.
RETURNED GOODS
CGS shall not accept returned goods unless authorized in
writing by CGS. Returned goods sent as Ex-Works will not
be accepted by CGS.
COMPLAINTS
Customer complaints must be made no more than 8 days
from reciept of goods. CGS will replace any defective product
but is not bound to provide additionalcompensation.
CGS is not responsible for damage caused by the customer’s
improper use or installation of the product.
COURT OF JURISDICTION
The buyer agrees that any and all disputes shall be settled
in the Court of Novara, Italy.
OUR LATEST OFFERS BY EMAIL
LATEST NEWS